Home Remodeling Contractor Agreement: Change Orders and Payment Schedules (Service Provider Guide)

Running a profitable remodeling business isn’t just about craftsmanship—it’s about controlling scope, documenting decisions, and collecting payment on time. Two contract areas determine whether a home renovation stays profitable: change orders and payment schedules.

As a remodeling contractor or construction company, you’ve likely experienced it: the homeowner “just wants a small tweak,” the designer swaps materials midstream, or site conditions force an unexpected fix. If your renovation contractor agreement doesn’t define how change orders work—or if your payment schedule doesn’t match real cash flow—you can end up financing the job, fighting over expectations, or chasing money after you’ve already delivered value.

This guide explains how to structure a home improvement contractor contract so that change orders are handled cleanly and payments are tied to progress—helping you reduce disputes, protect margins, and keep projects moving.

Note: This article provides general educational information. Contract terms vary by state and project type. Consider having counsel review your agreement for local compliance.

---

Why change orders and payment schedules matter (more than almost any other clause)

Most homeowner disputes come from two root problems:

1. Scope drift: The “same project” slowly grows into a different project.
2. Misaligned payments: You’re asked to perform labor or order materials without receiving funds that reflect the actual cost and risk.

A strong contract treats both as predictable business processes. When handled properly, change orders become a standard workflow—not a confrontation—and your payment schedule becomes a transparent roadmap for both sides.

---

Start with the right foundation: a clear home remodeling contract template

Many contractors rely on a generic home remodeling contract template or a downloadable remodel contract sample. Templates can be useful, but only if they address the real-world scenarios contractors face:

• Homeowner-driven upgrades (fixtures, finishes, layout changes)
• Hidden conditions (rot, mold, outdated wiring, failing subfloors)
• Schedule disruptions (permits, inspections, homeowner availability)
• Subcontractor price changes and long lead times
• Allowances and selections that get decided mid-project

If your template doesn’t force decisions into writing and tie work to payment, it’s not protecting your business.

A well-built home improvement contractor contract should include:

• Detailed scope of work (with inclusions/exclusions)
• Plans/spec references and a process for conflicts
• Change order procedure (written approval + pricing + schedule impact)
• Payment schedule tied to milestones or time
• Stop-work rights for nonpayment
• Allowances and selection deadlines
• Site access, owner responsibilities, and cleanliness
• Warranty language and manufacturer warranty pass-through
• Dispute resolution (mediation/arbitration or court, venue, attorney’s fees where allowed)

With that foundation, change orders and payments become easier to manage.

---

Change orders: the clause that protects your profit and your schedule

What is a change order in a home renovation?

A change order is a written modification to the original contract scope, price, and/or timeline. In remodeling, change orders typically arise from:

• Owner requests (“Add recessed lighting,” “Move the wall,” “Upgrade tile”)
• Plan/design clarifications and inconsistencies
• Unforeseen conditions discovered after demolition
• Code compliance upgrades required by inspectors
• Material availability substitutions (with owner approval)

The biggest mistake contractors make: starting change work without written approval

The “we’ll sort it out later” approach is where contractors lose money. Your renovation contractor agreement should clearly state:

• No change work begins until the owner signs a change order (or approves via defined e-sign method).
• The change order includes price (lump sum or time-and-materials), time impact, and payment timing.
• If the owner directs work orally or through a third party (designer/architect), it still requires written confirmation.

Contract language concept (plain-English):
“Contractor is not obligated to perform changes unless and until Owner authorizes a written Change Order describing the change, price adjustment, and time adjustment.”

Pricing change orders: lump sum vs time-and-materials

Your agreement should define how change orders are priced. Common approaches:

1) Lump sum change orders (best for clearly defined changes)

• Pros: Clear, easy for owner to understand
• Cons: Requires you to estimate quickly; risk if conditions change again

2) Time-and-materials change orders (best when scope is uncertain)

• Pros: Flexible and fair when unknowns exist
• Cons: Owners sometimes push back unless the contract is transparent

If you use T&M change orders, your contract should specify:

• Labor rates (standard, overtime, after-hours)
• Material markup (or handling fee)
• Equipment charges (dumpster, lift, specialty tools)
• Minimum service call charges (if applicable)
• Documentation (daily logs, receipts, timecards)

Markups: how to justify them without friction

Markups aren’t “extra”—they cover overhead, risk, supervision, warranty exposure, coordination, and business sustainability.

Your home improvement contractor contract should disclose how markups apply:

• Materials markup (e.g., 10–25% depending on project type/market)
• Subcontractor markup (commonly 10–20%)
• Change order admin fee (sometimes a flat fee)

The key is consistency and clarity. A good remodel contract sample should define markup in the change order clause rather than negotiating it in the middle of a job.

Schedule impact: change orders must adjust time, not just price

Change orders often affect:

• Permit revisions
• Lead times (custom cabinets, specialty tile)
• Sequencing (electrical after framing, paint after drywall, etc.)
• Inspection rework

Your contract should state that approved changes can extend the completion date and that time extensions may be granted for:

• Owner-requested changes
• Late selections
• Unforeseen conditions
• Delays outside contractor control (weather, supply chain, inspection scheduling)

Unforeseen conditions: treat them as a structured change order category

Remodeling exposes what’s behind walls—sometimes it’s perfect, sometimes it’s a mess. Your agreement should define “unforeseen conditions” and how you’ll proceed.

Best practice process:

1. Stop the affected area (if safety or integrity is at risk)
2. Notify owner with photos/documentation
3. Provide a change order (or a written directive with estimated range if urgent)
4. Proceed only upon approval (unless emergency protection is needed)

If emergency mitigation is required (e.g., active leak, unsafe wiring), your contract can allow limited immediate work to protect the property, with pricing handled promptly afterward.

Who can authorize changes?

Avoid “my spouse approved it” disputes. Define authorized parties:

• Owner(s) named in the contract
• Or a single designated decision-maker
• Designers/architects: clarify whether they can approve changes or only recommend them

Also include communication rules: email/text approvals count only if they meet defined requirements (e.g., “written approval includes email from Owner’s address acknowledging price/time”).

---

Payment schedules: align cash flow with real project risk

Why your payment schedule should reflect procurement and progress

Contractors commonly get squeezed when:

• Materials must be ordered early (cabinets, windows, tile)
• Subcontractors require deposits
• The owner expects “pay when it’s done”

A professional payment schedule in a renovation contractor agreement should reflect:

• Upfront mobilization and preconstruction time
• Long-lead procurement
• Labor and subcontractor progress
• Contingency for change orders and upgrades

Common structures: which one fits your remodel business?

1) Deposit + milestone payments (most common for fixed-price remodels)

Example milestones:

• Contract signing (deposit)
• Demo complete
• Rough-in complete (mechanical/electrical/plumbing)
• Drywall complete
• Cabinets installed
• Substantial completion
• Final completion (punch list + closeout)

Tip: Choose milestones that are objective and verifiable, not vague (“50% done”).

2) Progress payments on a schedule (weekly/biweekly)

This works well for:

• Larger projects
• Longer timelines
• Companies with robust reporting

Define:

• Billing cycle (e.g., every Friday)
• Payment due date (e.g., within 3 days)
• Late fees and stop-work rights

3) Payment tied to inspections (use cautiously)

Inspections can be delayed for reasons outside your control. If you tie payments to inspections, include a fallback:

• If inspection cannot be scheduled within X days, payment is due upon completion of work ready for inspection.

Retainage in residential remodeling: consider carefully

Retainage (withholding a percentage until completion) is more common in commercial construction, but some homeowners request it. If you agree:

• Keep it small (e.g., 5%)
• Release it at substantial completion or after defined closeout items
• Clarify that retainage doesn’t apply to change orders unless specified

Late payment protections: stop-work rights and interest

Your contract should provide real leverage:

• Payment due dates and grace period (if any)
• Late fees/interest where permitted
• Right to suspend work for nonpayment (with schedule extension and demobilization/remobilization costs)
• Owner responsible for costs caused by suspension (storage, protection, restocking)

These terms are not “aggressive”—they are standard risk management, especially when you’re carrying labor and materials.

Change order payments: do not wait until the end

One of the cleanest policies you can adopt is:

• Change orders are paid in advance, or
• Change orders are due immediately upon approval, or
• Change orders are added to the next progress invoice with no delay to payment terms

For material-heavy upgrades (custom items), require 100% of the cost before ordering.

This prevents the classic scenario: you install $8,000 of upgrades and then debate the invoice at the end.

Allowances and selection deadlines: avoid “budget surprise” disputes

Allowances are a frequent conflict point in any home remodeling contract template.

Your contract should clarify:

• Allowances cover material cost only or include tax/shipping
• Labor to install allowance items is included or separate
• What happens if the owner selects items over the allowance:
  • Difference is a change order
  • Potential schedule impact due to lead times
• Selection deadlines and what happens if the owner is late (default selection, schedule extension, or storage fees)

---

Putting it together: a practical workflow contractors can implement

Step 1: Use a consistent change order form

A good change order includes:

• Description of change (scope and location)
• Price change (add/deduct)
• Time impact (days added/removed)
• Payment due timing
• Owner authorization line (or e-sign)

Step 2: Set a “no signed change order, no work” culture

Train your team and subs:

• Field staff should not “promise” changes
• Any request triggers a documented process
• Keep communication professional and consistent

Step 3: Invoice predictably and tie invoices to the contract

Whether you use milestones or weekly billing:

• Invoice promptly
• Reference the contract milestone or billing period
• Include change orders as line items
• Provide supporting documentation where required (receipts, photos, daily logs)

Step 4: Use contract language that supports real jobsite decisions

Your contract should explicitly address:

• Site conditions and concealed defects
• Permits and inspection responsibilities
• Owner-provided materials (no warranty; schedule risk)
• Material substitutions (owner approval; schedule impact)

---

Common pitfalls in a remodel contract sample (and how to avoid them)

1. Vague scope descriptions (“Remodel kitchen”)
   Fix: Attach exhibits—plans, finish schedules, inclusions/exclusions.

2. No schedule change mechanism
   Fix: State that change orders may extend time and define excusable delays.

3. Payment schedule doesn’t match procurement
   Fix: Collect deposits for long-lead materials and create milestones around real cost events.

4. Allowances without rules
   Fix: Define what allowance includes and how overages are handled.

5. No stop-work clause
   Fix: Add the right to suspend work for nonpayment with cost/time adjustments.

---

Example payment schedule ideas (contractor-friendly)

Below are illustrative structures you can adapt to your home improvement contractor contract:

Option A: Milestone-based (fixed-price)

• 10–20% at signing (mobilization + preconstruction)
• 20% after demo + rough framing
• 20% after rough MEP complete
• 20% after insulation + drywall finish
• 15% after cabinets/trim
• 10% at substantial completion
• 5% at final completion (or after punch list, within a defined period)

Option B: Weekly progress billing (larger remodels)

• Deposit at signing (materials procurement)
• Weekly invoices for labor, subs, materials delivered
• Payments due within 3 days
• Change orders billed immediately upon approval

The “best” schedule is the one that keeps you cash-positive while still feeling fair and understandable to the homeowner.

---

FAQ: Other questions remodeling contractors ask (to keep learning)

• What clauses should be included in a renovation contractor agreement to limit scope creep?
• How do I write a change order clause that’s enforceable in my state?
• Should I use time-and-materials change orders or lump sum pricing for upgrades?
• What’s a reasonable deposit in a home remodeling contract template (and what do state laws allow)?
• How do I handle homeowner-provided materials in a home improvement contractor contract?
• What’s the best way to document delays caused by late selections or backordered items?
• Should my contract include mediation or arbitration for homeowner disputes?
• How do warranties work when the owner picks products vs when the contractor supplies them?
• What’s the difference between “substantial completion” and “final completion” in a remodel contract?
• How can I standardize my remodel contract sample across different project types (bath, kitchen, whole-home)?

---

Final takeaway: your contract should run the job, not just memorialize it

A strong contractor agreement is a project management tool. When your change order process is mandatory and your payment schedule mirrors your actual costs, you reduce disputes, protect profitability, and set expectations like a professional.

If you want a faster way to create or improve a home remodeling contract template—including clear change order and payment schedule language—consider using Contractable, an AI-powered contract generator built for real-world agreements. Learn more at https://www.contractable.ai.